shape-img

Terms & Conditions

These Terms and Conditions define the rules, obligations, and rights between Amirait™ and our clients. By engaging with our services, you agree to comply with the policies stated here to ensure a professional and lawful partnership.

Terms and Conditions

Effective Date: 29-Nov-2025

These Terms and Conditions outline the legal agreement between you (“the client”) and Amirait™ Dev Rise Global Technologies Pvt Ltd (“we,” “us,” or “our”). By accessing our website or using our services, you acknowledge that you have read, understood, and agree to be bound by these terms.

1. Services Provided

We specialize in delivering digital solutions, including website design and development, mobile application development, social media management, SEO, UI/UX design, and business automation tools. The exact nature and scope of services will be defined in a separate agreement or proposal shared with the client before project initiation.

2. Client Responsibilities

Clients are expected to actively participate in the success of their project by providing timely feedback, necessary resources (such as text, images, and login credentials), and approvals. Clients also agree that the materials they provide do not infringe upon any third-party intellectual property rights.

3. Project Timeline

We aim to deliver projects within the agreed timeline stated in the project plan. However, delivery times may vary based on scope changes, client delays, or unforeseen circumstances. We will communicate any necessary adjustments as early as possible and always strive to maintain reasonable delivery windows.

4. Payment Terms

Our payment terms are clearly outlined in project proposals. Most projects require a deposit to begin, with the remainder paid in milestones or upon completion. Failure to make timely payments may lead to suspension of work. All payments are non-refundable once deliverables are approved unless stated otherwise in a written agreement.

5. Intellectual Property Rights

Amirait™ retains ownership of all materials, code, and designs until the client has fulfilled their payment obligations in full. Once payment is complete, the client gains ownership of the final deliverables specific to the project. However, Amirait™ may still retain the right to use these works in our portfolio unless the client requests otherwise.

6. Confidentiality

All proprietary business information, credentials, or sensitive data shared by the client during the project will be treated as strictly confidential. Likewise, the client agrees to keep our proprietary processes, pricing, and proposals confidential. A separate NDA can be signed upon request.

7. Limitation of Liability

We are not liable for any indirect, incidental, or consequential damages arising from the use of our services. This includes but is not limited to loss of data, revenue, or business opportunities. Our maximum liability in any case will not exceed the total amount paid for the project.

8. Termination

Either party may terminate the agreement by providing written notice. If the client terminates the project after it has commenced, no refund shall be issued. Additionally, the project may be terminated in cases of non-cooperation, breach of contract, or non-payment

9. Governing Law

These Terms are governed by the laws of the Republic of India. Any disputes shall be subject to the exclusive jurisdiction of the courts in Dehradun/Uttarakhand.